DE PRIME INVESTMENT COMPANY PVT LTD
Welcome to DE PRIME INVESTMENT COMPANY PVT LTD. These terms and conditions outline the clear rules and guidelines for using our real estate development property management solutions and structural construction services. By working with us or using our services you fully agree to accept these terms in full.
DE PRIME INVESTMENT COMPANY PVT LTD is a registered organization operating under the Companies Act 2006 of Nepal. Our corporate office is located at Dahachowk Chandragiri Ward Number 1 Kathmandu. We provide formal property brokerage rental solutions asset management asset evaluation architectural design engineering supervision and complete home solutions within the framework of Nepalese law.
All land plots residential houses and commercial properties listed by our company are subject to rigorous verification. However final physical parameters land map plots boundary checkups and official property papers must be processed together with our field agents and the government land revenue office Malpot. Any booking amount paid to hold a specific land parcel or house will be managed according to the initial written token agreement form signed by both parties.
Before structural engineering house construction or renovation work begins a separate detailed contract document will be created. This official contract outlines the final architectural drawings exact material requirements cost estimations payment installments and estimated completion dates. Any modifications or addition of extra materials requested by the owner during the actual construction phase will influence the final cost and project delivery timelines.
Our complete home improvement service covers iron steel fabrication plumbing fixtures painting solar installations furniture setup and security systems. We strictly use durable materials sourced through our trusted local vendors. If a specific brand or interior asset is unavailable due to market supply drops we will present an alternative option of equal quality and value for your written approval before final setup.
For clients living outside of Nepal or non resident Nepalis NRNs we act as your local legal representative through a formal property management contract. We handle tenant selection rent collection background verification and basic house maintenance. Owners must provide accurate ownership credentials map layouts and ensure tax records are updated with the local municipality office before we initiate structural management.
We work with absolute financial honesty. All cost assessments and project fee divisions are shared upfront with zero hidden charges. Payments must be completed according to the milestone intervals agreed upon inside your service contract. Delayed installments can cause supply purchasing pauses or structural construction delay periods for which the company holds no liability.
For all new building projects local municipal office map approvals structural drawings approval Naksha Pass and regular land measurements are required. Our administrative desk helps compile documentation and checks legal requirements. The property owner must supply all necessary citizenship certificates original land titles Lalpurja and pay the required official government revenue taxes directly.
DE Prime strives to meet every project timeline on schedule. However our company is not responsible for construction delays triggered by force majeure situations including intense continuous monsoons road transport blockages local raw material supply drops strikes earthquakes or sudden changes in local municipal building rules.
Our long term customer commitment starts right at property handover. Specific components like code compliant electrical channels plumbing layouts customized wooden furniture settings and structural building elements carry limited maintenance support windows as specified inside your final hand over papers. Ongoing wear and tear or modifications handled by external independent contractors will void these corporate support guarantees.
Any misunderstandings differences of opinion or disputes arising from our real estate construction or property management dealings will first be addressed through mutual discussion and friendly local mediation. If a solution is not reached the matter will be settled under the corporate business rules and legal jurisdiction of the courts within Kathmandu Nepal.
